|
All Parties that use our web site (s), phone number (s,) or other services agree to the following terms and conditions of usage, and service, without exception. The following apply to All Companies associated with ConXerv Media LLC.
¨ All Parties that use our web site (s), phone number (s,) or other services agree to the following terms and conditions of usage, and service, without exception. The following apply NO Solicitations of any kind. This means sales calls, surveys, or any other un authorized use of our companies services, communications equipment, or staff. Should you decide to contact us anyway, you will be charged $50 per call, and $75 per hour of our staffs time. All invoices not paid will result in Additional legal, and collections costs being incurred. You will be responsible for All costs incurred in collecting any monies owed. ¨ We have the right to charge a minimum service fee, for any of our time spent dealing with you and your service request. This includes dealing with outside persons that you may involve in your on your behalf. All Administration time is billed @ $75 per man hour. . All invoices not paid will result in Additional legal, and collections costs being incurred. You will be responsible for All costs incurred in collecting any monies owed. ¨ Should you place a stop payment on any form of payment you agree to pay us three times the face value of that payment, plus All other additional labor, and costs incurred by us in the collection of this debt. Under no conditions may you stop payment to us. Terms of Service
¨ ConXerv LLC (contractor) agrees to perform the described work in a “workmanlike manner” to industry standards. To the best of their ability and skill. ¨ They also agree to leave the site in a “broom-clean condition”, upon completion of said project, unless otherwise noted. ¨ All permits are the Property Owners responsibility, unless otherwise noted in writing. And will require additional payment for permits, and labor to obtain them. Customer agrees to hold ConXerv LLC, its affiliates, and management harmless in regards to any permit requirements, should customer not pay for this service. ¨ All work is billed for actual hours, and all prices quoted are estimates. We cannot be responsible for unforeseen circumstances, the inability to obtain supplies, the weather, or any other delay. The customer agrees to pay for all services rendered, to complete the work described in the description of work section. All Work must be paid for as noted on the bid, or at the completion of each day. Work maybe stopped, or delayed until payment is made. ¨ If the actual labor or materials is to exceed $500 above said estimate ConXerv LLC will notify the Customer as soon as they are aware of the situation. At which point the customer may elect to pay for services rendered, and not move any farther with said project, through Contractor. All “notice to stop work” shall be mailed return receipt requested to Box 5472, Denver Colorado 80217. Any notices not sent to above address shall be considered null and void. Failure to use this manor to discontinue services with ConXerv LLC shall result in the customer owning the entire amount of the contract, becoming due and payable immediately. ConXerv LLC may require additional payments from time to time throughout said project. Should the customer not pay Upon receipt of invoice, ConXerv LLC may elect to suspend any and all work on said project, until the account is brought current. ConXerv LLC may at this point require advanced payment for all additional services. Customer agrees to pay a “dispute labor fee” of $75 per man hour, for any and all labor extended to recover all past due debts; in addition to all other expenses incurred, at cost plus 25%. This includes additional labor necessary to contend with Outside entities, brought in by the customer. ¨ Customer agrees to pay the balance promptly, and/or noted on contract. Customer agrees to pay “three times the face value” return check fee, and all costs of collection including but not limited to attorney fees, postage, and in-house labor to collect all amounts due. All Prices estimated are cash Prices. Personal Checks are not accepted. ConXerv LLC reserves the right to refuse any check, and as policy does not accept checks, including out of state checks. Management shall reserve the right to require certified funds for any payment, or to refuse to accept as payment any check. Business checks will incur a 5% surcharge. There shall be a $35 late fee, as well as compound interest of 24% for all monies not paid upon receipt of invoice, or the maximum allowed by law. ¨ Should the ConXerv LLC decide to post a “notice of intent to lien”, customer shall incur a $300 “lien Fee”. Posting shall be at the discretion of ConXerv LLC. ¨ Customer agrees to provide all necessary access, and that should ConXerv LLC not be able to gain said access, customer shall be responsible for a $100 “no access fee”. Should the customer decide to cancel an appointment, they will need to do so prior to dispatch of crew, or they will be responsible for a service call charge. Customer also agrees not to deny access to any tools or other property belonging to ConXerv LLC, and that such denial shall cost the customer $100 “no access fee”. Customer shall be responsible to replace any tools not returned, or missing, at customers sole expense. The determination of access shall be at ConXerv LLC’s sole discretion. ¨ If material is to be supplied by the customer, customer agrees to have all material on site accessible prior to the commencement of said project. Should at any time during the project, ConXerv LLC not be able to access material, customer agrees to pay for all additional labor incurred, as a result. Should ConXerv LLC obtain any material it will be charged to the customer at cost plus 20%, plus all labor to obtain. ¨ Customer Agrees not to have any other contractor on said job site until ConXerv LLC completes said job, unless written permission is provided by ConXerv LLC Management. Failure to obtain consent shall result in a $100 “competition fee” being assessed to the customer, per individual on site, per day, in addition to any damages incurred. This also applies to solicitation of vendors and sub-contractors. This shall be at the sole discretion Of ConXerv LLC. ¨ ConXerv LLC does not guarantee the completion date of this project, unless a “guaranteed completion date contract” has been completed, and paid for. All completion date guarantees, must be in writing, and on said form. All other guarantees expressed or implied are null and void. ¨ ConXerv LLC shall not be liable if customer or anyone should become injured on said project site. As well as ConXerv LLC shall not be liable for any acts of vandalism or theft during the course of said project. ConXerv LLC shall not be liable for any consequential or punitive damages, at any time. Customer shall provide security, and shall be liable for any and all tools missing, or stolen from said project. This Shall be determined solely by ConXerv LLC management. ¨ In the unlikely event that a dispute should arise, customer agrees to arbitration, in the state of Colorado, Park County, for any disputes brought against ConXerv LLC or any one associated with ConXerv LLC. ConXerv LLC Reserves the right to pursue civil action to enforce this contract. In a jurisdiction of ConXerv LLC Choice. The customer shall be liable for three times the face value of said contract, in the event of nonpayment, or disputes. Plus any and all other costs as outlined in this contract, or other damages as granted by the courts. All collections costs shall be added to the value of this contract. It is further agreed that The maximum amount that ConXerv LLC, it’s employees, Contractors, Sub-contractors, or any other agent of ConXerv LLC; both severally and collectively, shall be liable for in any event shall be the amount that has been paid from the customer to ConXerv LLC. ¨ Should the work described in the work description area of the estimate be done at our shop, or other facility operated by ConXerv LLC, or one of its affiliates, the customer agrees to a “mechanics’ lien” being applied until paid in full. Customer also agrees that should whatever Item not be picked up within 72 hours of notification, customer shall be responsible for $22 per day storage fees. Beginning on the date of the original contract. All fees, and monies owed must be paid prior to Item being released. Failure to payment being made with in 30 days shall result in said item being sold and the sale price being applied to the account. The remaining balance of the contract shall remain due, and payable. Both parties agree that this is the entire contract, and that all other statements, and contracts are null and void. ConXerv LLC is not responsible for typographical errors, and maintains the right to correct any and all such errors. to All Companies associated with ConXerv Media LLC.
Service Providers
¨ We will supply, as outlined in our agreement you with leads or projects. ¨ No guarantee is expressed or implied as to the usefulness of any leads generated by us. ¨ All affiliates, providers, sub contractors, or others are responsible to provide their own insurance. This includes liability, and “work mans compensation”. Copies must be on file in ConXerv LLC offices prior to work being commenced. Failure to do so shall not absolve you of the responsibility to do so. ¨ No out of state checks will be accepted, all payments must be money order or local checks. ¨ You may not take, solicitation, or do “side work” for any customer of ours. Should you attempt to do so, you shall pay us twice the value of the project, as determined by ConXerv LLC management. ¨ You shall perform all work in accordance with your contact with us, and should you fail to do so, you shall pay for all of our expenses, including our administrative, legal, and collections costs. ¨ You shall ad hear to the customer terms of service, at all times ¨ All decisions made by ConXerv management are final. ¨ You agree to a drug and alcohol Free work, jobsite and to and from the Job site environment. ¨ Should a dispute arise you agree to mediation in Park County Colorado. ¨ ConXerv LLC, nor any of its affiliates shall not be liable for any more than amounts paid to said entity. ¨ You agree to a $300 administration plus collections fees, should ConXerv LLC elect to turn over any past due account to collections. This shall be at the sole discretion of ConXerv LLC management.
Both parties agree that this is the entire contract, and that all other statements, and contracts are null and void. ConXerv LLC is not responsible for typographical errors, and maintains the right to correct any and all such errors. |
|
Homes Retailer.com |
|
The One Stop Real Estate Solution |
|
This Site is owned and operated by ConXerv Media LLC. ALL RIGHTS RESERVED. NO Unauthorized use permitted. Including Solicitation of commercial interests to the respective company. Any Unauthorized Use will result in full prosecution, and legal action to seek damages. The information provided in this site is property of the company providing said services in your area. ConXerv Media LLC is by no means responsible for any of the services, or how they are represented. Please contact the provider for additional information. Should you wish to advertise with, or to increase your web presence, feel free to contact us Here. Thank You for choosing US!
|
|
303-997-1784 1-877-286-6902
Loans 303-997-1709 |